Evaluation of the Causal Factors and Impact of Contract Change Orders (CCO) on the Implementation of Building Construction Projects
DOI:
https://doi.org/10.37253/jcep.v7i1.12099Keywords:
Contract Change Order (CCO), Factors Causing CCO, Impact of CCO, Influence DiagramAbstract
Contract Change Order (CCO) is a contract change in a construction project where there is additional work to adjust the field volume or schedule changes without changing the contract articles. This study aims to identify the factors causing CCO and evaluate the impact of CCO on the implementation of government building construction projects in West Tulang Bawang Regency using the Influence Diagram method. Based on the results of the analysis that has been done, there are seven main factors that cause CCO, namely: design errors, incomplete drawings, errors in field implementation, errors in implementation methods, weather factors, soil conditions, and price fluctuations. CCO is carried out in 3 ways, namely: revising the design, revising the Cost Budget Plan (RAB), and revising the schedule (S curve). The impacts that occur after the CCO on this project are volume adjustments, time delays, decreased productivity and the potential for conflict. The impact caused by volume adjustments causes changes in material specifications, unit costs and the need for additional work to be done so that it does not change the contract value of the work. The impact caused by the 10-day delay in completion time results in the contractor having to pay a fine of Rp. 280,449,811.50. The impact of quality adjustments can lead to improved specifications, thus improving the quality of work. Another impact of CCO is the potential for conflict, which, if not resolved properly, can escalate to legal proceedings.
Downloads
References
S. F. Yunita Mauliana, Mirnanda Cambodia, Manajemen Konstruksi, 1 ed. Sumatera Barat: Yayasan Pendidikan Cendekia Muslim, 2023.
F. Ferry dan I. Indrastuti, “Penerapan building information modelling (BIM) pada proyek pembangunan workshop (Studi kasus: Proyek pembangunan workshop kapal di Sekupang),” J. Civ. Eng. Plan., vol. 1, no. 1, hal. 7, 2020.
K. D. Lakaoni dan M. Waty, “Dampak change order proyek konstruksi bangunan gedung bertingkat sedang,” JMTS J. Mitra Tek. Sipil, hal. 367–382, 2023.
M. Pamadi, U. Hayadi Umar, dan N. Chen, “Analisis Penjadwalan Proyek Menggunakan Metode EVA (Earned Value Analysis) pada Proyek Pembangunan Ruko De Monde Junction-Pasir Putih, Batam,” J. Civ. Eng. Plan., vol. 2, no. 2, hal. 188–202, 2021.
H. E. Putra dan H. Sulistio, “Pengaruh Change Order Terhadap Biaya, Mutu, Dan Waktu Pada Proyek Konstruksi Gedung Bertingkat,” JMTS J. Mitra Tek. Sipil, hal. 1349–1362, 2020.
J. Susilo, “Analisis Faktor-Faktor Perubahan Desain Yang Mempengaruhi Waktu, Biaya Dan Mutu Pada Proyek,” Tugas Akhir, Univ. Semarang, 2021.
A. Maulana, “Faktor penyebab terjadinya contract change order (CCO) dan pengaruhnya terhadap pelaksanaan proyek konstruksi pembangunan Bendung,” J. Infrastruktur, vol. 2, no. 2, hal. 40–51, 2016.
Peraturan Presiden Republik Indonesia, No. 12 Tahun 2021 tentang Perubahan Atas Peraturan Presiden Nomor 16 Tahun 2018 Tentang Pengadaan Barang/Jasa Pemerintah.
Peraturan Presiden Republik Indonesia, Peraturan Presiden No.16 tahun 2018 pasal 54 tentang Pengadaan Barang/Jasa Pemerintah ayat (1).
Peraturan Presiden Republik Indonesia, Peraturan Presiden No.16 tahun 2018 pasal 54 tentang Pengadaan Barang/Jasa Pemerintah ayat (2).
T. Hsieh, S. Lu, dan C. Wu, “Statistical analysis of causes for change orders in metropolitan public works,” Int. J. Proj. Manag., vol. 22, no. 8, hal. 679–686, 2004.
Salwa Inka Yunisa; Veronika Happy Puspasari, “Analisis Faktor-Faktor Penyebab Contract Change Order (CCO) Pada Proyek Konstruksi di Kota Palangka Raya,” Basement J. Tek. Sipil, vol. 2, no. 2, hal. 132–140, 2024, doi: 10.36873/basement.v2i2.15294.
D. Daniel dan M. Waty, “Penyebab change order proyek konstruksi rumah sakit,” JMTS J. Mitra Tek. Sipil, hal. 429–440, 2023.
M. R. A. Atallah dan I. H. Saputra, “Analisis Pengaruh Contract Change Order (CCO) Terhadap Penyelesaian Waktu Pekerjaan Proyek Gedung Pusat Terpadu Kabupaten Sidoarjo,” in Seminar Nasional Teknik Sipil, 2024, hal. 101–115.
A. D. Kuswandari, A. Koesmargoro, dan W. I. Ervianto, “Pengaruh Dampak Contract Change Order Terhadap Kinerja Kontraktor Proyek Studi Kasus: Rehabilitasi Jembatan Ngablak,” J. Tek. Sipil, vol. 14, no. 4, hal. 255–282, 2018.
K. Hapsari dan V. Suhandi, “Usulan Peningkatan Kapasitas dengan Meningkatkan Kinerja Lini Produksi Melalui Model Simulasi (Studi Kasus di PT X, Bekasi),” J. Integr. Syst., vol. 1, no. 1, hal. 1–19, 2018.
S. T. Ani Kusumaningsih, M. M. D. M. Hasan, S. E. Muhammad Ismail, dan S. P. Nurdiana, “PENGAMBILAN KEPUTUSAN DALAM BISNIS”.
R. Aurachman, “Perancangan influence diagram perhitungan dampak dari revolusi industri 4.0 terhadap pengangguran kerja,” J. Teknol. dan Manaj. Ind., vol. 4, no. 2, hal. 7–12, 2018.
Downloads
Published
Issue
Section
License
Copyright (c) 2026 Sukarsih, Yunita Mauliana
This work is licensed under a Creative Commons Attribution 4.0 International License.
.png){kind=small}
